A⇡ Yazı karakterini büyüt ᴀ⇣ Yazı karakterini küçült
Sayfa numarasını gizle
Bağlantılar
Aşağıda bir kısmını gördüğünüz bu dokümana sadece pakete abone olan üyelerimiz erişebilir.
H.Örnek Satım Sözleşmesi
SALE CONTRACT…
This Agreement is made on 30th November 2024 between…
(Insert the name and the address of the Buyer) (hereinafter Buyer)…
and…
(Insert the name and address of the Seller) (hereinafter Seller)…
Whereas the Seller is a company manufacturing and exporting of the product,
Whereas the Buyer has decided to procure equipment to the scope of supply defined in the Seller’s offer,
Whereas the Seller undertakes the terms, form and time limits determined by the Parties in the Contract,…
Whereas the Seller has submitted the proposal for supply of theses machinery and equipment,…
Whereas the Buyer has agreed to accept the proposal for supply of the said machinery, equipment and services on the terms and conditions stated hereinafter,…
And whereas the Seller, has agreed to supply the said equipment and services on the terms and conditions as agreed hereinafter.…
Whereby it is agreed as follows:…
1. DEFINITIONS…
Unless the context otherwise requires, the following expressions shall have the meanings hereby assigned to them:…
“Contract” shall mean this Contract entered into force between the Buyer and the Seller for procurement of the Equipment.…
“Equipment” Means the items of Equipment as described in Technical Conditions.…
“Terms And Conditions” means the Seller’s General Terms and Conditions of Sales Version annexed hereto.…
“Warranty Period” means the period defined in clause 8 of the present Contract.…
2. SCOPE OF THE CONTRACT…
For the purposes of execution of this Contract, the Seller undertakes to supply the Equipment described in annex (X). The Buyer is responsible for all payments made for the Project regarding the Equipment, Work and Supervision and the opening of the Letter of Credit.…
3. PRICES…
The contract price quoted for the Equipment and the Works as follows:…
Unit based prices for Desalination Units are given in Annex-Ol «Desalination Units Delivery List».
Name
Qty
Unit price
Total Price
Price for … Units according to Annex-I ,
… Unit
…
…
USD
Price for … according to Annex-I ,
… Unit
…
…
USD
Total Contract Price FOB
…
USD
The Contract Price is excluding VAT and other fees.…
4. PAYMENT TERMS…
The payment for the delivered goods should be made in US dollars. The Seller makes the transfer of advance payment in the amount of …. whenever counter guaranty of correspondent bank is available.…
The rest of the amount to be paid to the “Seller” by an irrevocable and unconditional Letter of Credit. The Letter of Credit shall be opened not later than 15 (fifteen) Days before the Scheduled Shipment Date. All charges associated with opening the Letter of Credit shall be borne by the Buyer.…
5. DELIVERY SCHEDULE…
The Equipment shall be delivered according to Annex No. 1. All delivery times are valid after the signing of the contract by the reciprocal parties.…
6. DELAY IN DELIVERY…
If at any time during performance of the Contract, the Seller should encounter conditions impeding timely Delivery of the Equipment and services, the Seller shall promptly notify the Buyer in writing of the fact of delay, its likely duration and its causes.…
If the Seller fails to deliver the goods/services within the agreed-upon delivery timeframe specified in this agreement, the Buyer shall be entitled to impose a late delivery penalty.…
The late delivery penalty shall be calculated as a percentage of the total contract value for each day of delay beyond the agreed-upon delivery date. The specific percentage for the late delivery penalty is [insert the agreed percentage, e.g., 0.5%] per day.…
The maximum cumulative late delivery penalty shall not exceed [insert the maximum limit, e.g., 10%] of the total contract value.
7.PACKING AND SHIPMENT…
The Equipment shall be packed in seaworthy packing of international standard so as to protect the packages from damage in transit by shipment.…
Partial shipment and Transshipment are allowed.…
The Seller shall supply the Equipment as defined in the Contract. The Seller shall guarantee the figures as defined.…
G.Cezai Şart veya Götürü Tazminat (Penalty or Liquidated Damages)
EN
TR
